Terms and Conditions

This website is operated by NPD Management Pty Ltd ACN 088 099 254, Acquavista Pty Ltd ACN 637 708 297 their related bodies corporate and their officers, employees, and agents (Pask).

To contact us, please email privacy@nevpask.com.au or contact the Privacy Officer on 07 5531 2399.

By using our website, you confirm that you accept these terms of use and that you agree to comply with them. If you do not agree to these terms, you must not use our website.

We may amend our website terms and make changes to our website from time to time without notice.

Any maps, plans and images on this website are for general and illustrative purposes only, are not to scale and may not be exact or accurate. The final product may differ from that illustrated. Maps, plans and images contained on this website may depict fixtures, finishes and features such as furnishings and landscaping which are not included in the house designs or land lots and are not supplied by Pask. Accordingly, any prices displayed do not include the supply of those items. Actual specifications for a particular house may vary and will be set out in any sales contract. Plans are subject to final design, feasibility and council approvals. For detailed house pricing and specifications please contact the sales agent. Pask reserves the right to substitute fixtures and finishes with other  fixtures and finishes of a comparable quality at its absolute discretion and may alter its suppliers at any time without notice. Reference to expected completion timeframes are provided as a guide only. Actual completion dates may vary due to market and weather conditions, availability of resources, delays in approvals or other factors.

Pricing and availability are subject to change at any time without notice. Prospective purchasers should undertake and rely on their own independent enquiries for their own benefit and satisfaction before proceeding with any investment. Any investment will be subject to the terms of any contract of sale and formal disclosure statements. Prices displayed do not include transfer duty, legal fees or other costs that may be incurred in connection with any investment. Any reference to price is to Australian currency.

None of the information or other content on this website takes into account an individual’s financial objectives, situations or needs, and should not be construed as financial advice.

You may use the website only for lawful purposes and in accordance with these terms.

Information on this website is believed to be accurate but is subject to change at any time without notice. No warranty or representation (implied or express) is given as to the accuracy, reliability or completeness of the information or other content contained on this website. To the extent permitted by law, Pask excludes all liability for any inaccuracies in, or incompleteness of, the information and other content included on this website or for any loss or damage (including special, indirect, or consequential loss or damage such as loss of revenue or profit) to any person which arises as a result of any use of, inability to use, or reliance on the information or other content contained on, this website or otherwise in connection with it.

Pask does not guarantee that this website, or any content on it, will always be available, uninterrupted or be error-free or that the website will be secure or free from bugs or viruses or any other type of malicious code or software. We may suspend or withdraw or restrict the availability of all or any part of our website for business and operational reasons. We will try to give you reasonable notice of any suspension or withdrawal.

This website may contain links to other websites operated by third parties (“Third Party Websites”). Pask does not control, endorse, or approve of the operators of Third Party Websites, or the information, graphics, materials, products and services offered on those Third Party Websites. Links to Third Party Websites are provided for convenience only. If you access or use the products or services available at Third Party Websites, you do so solely at your own risk.

This site includes registered trade marks and trade marks which are otherwise protected by law. Unless otherwise indicated, these trade marks are owned by Pask in Australia. You must not use any of the Pask trade marks or business names except with the prior written consent of Pask.

Unless indicated otherwise, the contents of this website are protected by copyright under the laws of Australia and, through international treaties, other countries, and Pask reserves all of its rights in that regard. The material on this website may be downloaded for personal use only and may not be used for any other purpose without the prior written consent of Pask. You must not reproduce, transmit, adapt or otherwise exercise the copyright in the whole or any part of this website except with the prior written consent of Pask.

This website (excluding any linked Third Party Websites) is controlled by Pask in Queensland, Australia. By accessing this site, you accept that any disputes about this website or its contents are to be determined by the Courts having jurisdiction in Queensland in accordance with the laws of Queensland, provided that any dispute arising relating to any of Pask’s projects located in Victoria is to be determined by the Courts having jurisdiction in Victoria and in accordance with the laws of Victoria.

This website may be accessed throughout Australia and overseas. Pask makes no representation that the content of this website is appropriate or available for us in any country outside Australia. If you access this site from outside Australia, you do so solely at your own risk and you are responsible for ensuring compliance with all laws in the place where you are located.

 

 

Register your interest to receive
all the latest information

Stotts Hill - Registration Form








Commencement of bulk earthworks

Following receipt of all necessary approvals, Pask’s appointed civil contractor will mobilise to site to remove any existing structures and commence bulk earthworks.

Within this phase, machinery is used to shift large quantities of soil and rock, to enable the subsequent phases of the civil construction process to occur. To reduce waste, this material is often stockpiled and reused in the later phases.

Construction of sewer & drainage and installation of water & gas

Large trenches are excavated to allow for the installation of sewer and drainage infrastructure. These works generally connect into and extend trunk infrastructure from existing areas, to then enable the creation of individual connection points for all lots within the stage.

Following the installation of sewer and drainage infrastructure, water, recycled water, and gas (where applicable) services are installed.

Construction of roads, kerb, and channel

A foundation layer known as subgrade is placed to ensure the stability and durability of all roads within the stage.

This process is followed by the construction of kerb and channel – a structure located on both sides of the road, which will act as both a protective barrier and drainage system to manage stormwater flows.

Installation of electrical and communication infrastructure

Parallel to the newly completed kerb and channel, a trench is excavated to allow for the installation of electrical and communications conduits. This enables the installation of applicable cabling to follow, ensuring all lots are equipped for electrical and telecommunications services.

Construction of footpaths, asphalt to roads and topsoiling

With all underground infrastructure installed, footpaths are poured, and a final layer of asphalt is applied and sealed to all roads. Lots are then topsoiled to accord with finished surface levels, in line with approved engineering plans.

Construction completion and request for authority approvals

At the completion of civil construction, the municipal council undertake an assessment to confirm the completed works are in accordance with approved engineering designs for that stage.

Formal approval or ‘Practical Completion’ is required prior to Pask and its consultant team seeking final approval from the relevant service authorities (ie. Melbourne Water, Powercor/Jemena etc). Once all authority approvals are received, a final endorsement known as ‘Statement of Compliance’ is issued.

Title registration and settlements

The issuance of Statement of Compliance enables a certified Plan of Subdivision to be lodged with Land Victoria for assessment and approval.

This approval will result in the formal registration of all individual lot titles for the stage. At such time, we will issue correspondence to your legal representative with an accompanying request to schedule settlement.

Stage 1
0% Complete

Title Registration:
Q2 2024 (Estimated)

Construction Phases

  • Authority Approval
  • Earthworks
  • Sewer & Drainage
  • Water & Gas
  • Subgrade
  • Kerb & Channel
  • Electrical & NBN
  • Footpaths & Asphalt
  • Construction Completion
  • Statement of Compliance
  • Titles & Plan Registration

Expected timeframes are provided as a guide only. Actual completion dates may vary due to market and weather conditions, availability of resources, delays in approvals or other factors.
Note – ‘% Complete’ relates to overall stage progress.

Construction Phases